X

Thank you for sharing!

Your article was successfully shared with the contacts you provided.
APPEAL FROM THE UNITED STATES DISTRICT COURT FOR THE DISTRICT OF MAINE [Hon. D. Brock Hornby, U.S. District Judge]

During the construction of a shipbuilding facility in Bath, Maine, a series of events, primarily attributable to the caprices of nature, delayed the schedule, forcing significant alterations to the work plan and ultimately making the project more expensive than had been anticipated. These events led to a dispute between the project’s dredging subcontractor, Inner Space Services, Inc. (“ISSI”), and the drilling and blasting subcontractor it had hired, Northeast Drilling, Inc. (“NDI”), over who should bear the additional costs arising from these various matters. Following a six-day bench trial, the district court determined that NDI should receive some of the payments it claimed were due under its contract with ISSI, but that it was not entitled to the full amount because it had failed to render complete performance under its agreement with ISSI. The court also awarded attorney’s fees and interest to NDI.

On appeal, ISSI challenges a number of the district court’s factual findings, and argues that the court erred by declining to make certain additional findings. ISSI also assigns error to several legal determinations made by the district court, including the district court’s failure to join the general contractor as a party, its refusal to grant ISSI’s motion for judgment as a matter of law, and its approach to calculating damages. We affirm in all respects.

 
Reprints & Licensing
Mentioned in a Law.com story?

License our industry-leading legal content to extend your thought leadership and build your brand.

More From ALM

With this subscription you will receive unlimited access to high quality, online, on-demand premium content from well-respected faculty in the legal industry. This is perfect for attorneys licensed in multiple jurisdictions or for attorneys that have fulfilled their CLE requirement but need to access resourceful information for their practice areas.
View Now
Our Team Account subscription service is for legal teams of four or more attorneys. Each attorney is granted unlimited access to high quality, on-demand premium content from well-respected faculty in the legal industry along with administrative access to easily manage CLE for the entire team.
View Now
Gain access to some of the most knowledgeable and experienced attorneys with our 2 bundle options! Our Compliance bundles are curated by CLE Counselors and include current legal topics and challenges within the industry. Our second option allows you to build your bundle and strategically select the content that pertains to your needs. Both options are priced the same.
View Now
December 02, 2024 - December 03, 2024
Scottsdale, AZ

Join the industry's top owners, investors, developers, brokers and financiers for the real estate healthcare event of the year!


Learn More
December 11, 2024
Las Vegas, NV

This event shines a spotlight on how individuals and firms are changing the investment advisory industry where it matters most.


Learn More
February 24, 2025 - February 26, 2025
Las Vegas, NV

This conference aims to help insurers and litigators better manage complex claims and litigation.


Learn More

We are seeking two attorneys with a minimum of two to three years of experience to join our prominent and thriving education law practice in...


Apply Now ›

Description: Fox Rothschild has an opening in the New York office for a Real Estate Litigation Associate with three to six years of commerci...


Apply Now ›

Downtown NY property and casualty defense law firm seeks a Litigation Associate with 3+ years' experience to become a part of our team! You ...


Apply Now ›