X

Thank you for sharing!

Your article was successfully shared with the contacts you provided.

Ray, Presiding Judge.In 2013, Fulton County (the “County”) and SOCO Construction Company, Inc. (“SOCO”) executed a written contract for the construction of a cultural center. The contract was approved by the Fulton County Board of Commissioners. As a result of several delays, including those caused by change orders, inclement weather, and the shutdown of the federal government, the scope of the work and time line was altered.   SOCO filed the instant complaint against the County for, inter alia, breach of contract and bad faith performance of the contract. SOCO also sought attorney fees and injunctive relief. Soco and the County filed cross-motions for summary judgment on all claims. The trial court granted summary judgment in favor of SOCO and against the County.[1] In the same order, the trial court also denied the County’s motion for reconsideration of its denial of the County’s motion to withdraw admissions.We reverse the trial court’s denial of the County’s motion for summary judgment on the grounds that any claims arising from unwritten change orders are barred under the doctrine of sovereign immunity. Further, we affirm in part and reverse in part the trial court’s order denying the County’s motion for reconsideration of its motion to withdraw admissions. Finally, we vacate and remand the trial court’s ruling on attorney fees.To prevail at summary judgment, the moving party must demonstrate that there is no genuine issue of material fact and that the undisputed facts, viewed in the light most favorable to the nonmoving party, warrant judgment as a matter of law. . . . We conduct a de novo review a trial court’s grant of summary judgment.

(Citations and punctuation omitted.) Bright v. Sandstone Hospitality, LLC, 327 Ga. App. 157, 157-158 (755 SE2d 899) (2014).   In May 2013, the County and SOCO executed a written contract for the construction of the Aviation Community Cultural Center near the Fulton County Airport. The contract specified that the work should be completed within 287 days from the County’s issuance of the notice to proceed or the day the work began, whichever came first, with that period to be increased by change order due to changes in the scope of work, or upon the occurrence of other delays or events not the fault of the contractor. Section 00700-87A of the “General Conditions” portion of the contract provides that[a] Change Order is a written order to the Contractor signed to show the approval and authorization of the County, issued after execution of the Contract, authorizing a change in the Work and/or an adjustment in the Contract Sum or the Contract Time. Change Orders shall be written using forms designated by the County with Contractor providing supporting documentation as required by the Construction Manager. The Contract Sum and the Contract Time may be changed only by approved Change Order pursuant to Fulton County Procedure 800-6. . . . A Change Order signed by the Contractor indicates the Contractor’s agreement therewith, including the adjustment in either or both of the Contract Sum or the Contract Time.

 
Reprints & Licensing
Mentioned in a Law.com story?

License our industry-leading legal content to extend your thought leadership and build your brand.

More From ALM

With this subscription you will receive unlimited access to high quality, online, on-demand premium content from well-respected faculty in the legal industry. This is perfect for attorneys licensed in multiple jurisdictions or for attorneys that have fulfilled their CLE requirement but need to access resourceful information for their practice areas.
View Now
Our Team Account subscription service is for legal teams of four or more attorneys. Each attorney is granted unlimited access to high quality, on-demand premium content from well-respected faculty in the legal industry along with administrative access to easily manage CLE for the entire team.
View Now
Gain access to some of the most knowledgeable and experienced attorneys with our 2 bundle options! Our Compliance bundles are curated by CLE Counselors and include current legal topics and challenges within the industry. Our second option allows you to build your bundle and strategically select the content that pertains to your needs. Both options are priced the same.
View Now
May 01, 2025
Atlanta, GA

The Daily Report is honoring those attorneys and judges who have made a remarkable difference in the legal profession.


Learn More
February 24, 2025 - February 26, 2025
Las Vegas, NV

This conference aims to help insurers and litigators better manage complex claims and litigation.


Learn More
March 24, 2025
New York, NY

Recognizing innovation in the legal technology sector for working on precedent-setting, game-changing projects and initiatives.


Learn More

ABOUT THIS RECRUITMENTOur attorneys face some of the most challenging, cutting-edge legal issues in the environmental field. As such, we ar...


Apply Now ›

Hofstra University enrolls over 6,000 undergraduate students and nearly 4,000 graduate students in 13 schools, which feature a variety of de...


Apply Now ›

McCarter & English, LLP is actively seeking a patent associate, patent agent, or technical specialist for its Intellectual Property Prac...


Apply Now ›