10952. KLEINBERG ELECTRIC, INC., plf-ap, v. E-J ELECTRIC INSTALLATION CO. def-res — Goulston & Storrs, P.C., Boston, MA (Derek B. Domain of the bar of the State of Massachusetts, admitted pro hac vice, of counsel), for ap — Gallet Dreyer & Berkey, LLP, New York (Randy J. Heller of counsel), for res — Judgment, Supreme Court, New York County (O. Peter Sherwood, J.), entered November 8, 2012, after a nonjury trial, awarding defendants damages, and bringing up for review an order, same court and Justice, entered August 25, 2011, which, insofar as appealed from as limited by the briefs, granted judgment in defendants’ favor on their counterclaim, and an order, same court and Justice, entered October 2, 2012, which found that defendants were entitled to $570,935.00 for overpayment damages and $1,165,263.00 for cost-to-complete work damages, for a total sum of $1,736,198.00 plus interest, costs and disbursements, unanimously modified, on the facts, to vacate the award of $570,935 for overpayment damages, and otherwise affirmed, without costs.
Defendants are entitled to cost-tocomplete damages because plaintiff materially breached and abandoned the subcontract, and waived any right to notice of termination or an opportunity to cure. The subcontract explicitly provides that time is of the essence, that plaintiff’s delay or failure to meet scheduling requirements warrants termination, and that plaintiff must perform work even if the parties dispute that work’s characterization, yet plaintiff repeatedly failed to timely perform and complete work, despite defendant E-J Electric Installation Co.’s repeated demands (see Engels v. French, 274 AD2d 544 [2d Dept 2000]). Among other material breaches, plaintiff repudiated the subcontract by abandoning the work site when only 73.49 percent of plaintiff’s work was complete (see Norcon Power Partners v. Niagara Mohawk Power Corp., 92 NY2d 458, 462-463 [1998]; General Supply & Constr. Co. v. Goelet, 241 NY 28, 34 [1925]; Plato Gen. Constr. Corp./EMCO Tech Constr. Corp., JV, LLC v. Dormitory Auth. of State of N.Y., 89 AD3d 819, 824 [2d Dept 2011], lv denied 19 NY3d 803 [2012]; Remodeling Constr. Servs. v. Minter, 78 AD3d 1677, 1678 [4th Dept 2010]). Accordingly, plaintiff waived any right to notice of termination (see J. Petrocelli Constr., Inc. v. Realm Elec. Contrs., Inc., 15 AD3d 444, 446 [2d Dept 2005]; Special Situations Fund III v. Versus Tech., 227 AD2d 321 [1st Dept 1996], lv denied 88 NY2d 815 [1996]; Sunshine Steak, Salad & Seafood v. W.I.M. Realty, 135 AD2d 891, 892-893 [3d Dept 1987]).
