X

Thank you for sharing!

Your article was successfully shared with the contacts you provided.

The following e-filed documents, listed by NYSCEF document number (Motion 006) 76, 77, 78, 79, 80, 81, 82, 83, 84, 85, 86, 87, 88, 89, 90, 91, 92, 93, 94, 95 were read on this motion to/for JUDGMENT-DEFAULT. DECISION + ORDER ON MOTION In this action for, among other things, breach of contract, EIGHTEEN HARRISON MANAGEMENT LLC (“plaintiff”) moves, by notice of motion dated April 9, 2024, for leave to enter a default judgment against GRUPPO 5 SUBPARTNERS INC., (“defendant”) in the amount of $724,634.94, together with costs and interest. Defendant submits no opposition to this motion. For the reasons set forth below the court grants the motion. BACKGROUND Plaintiff EIGHTEEN HARRISON MANAGEMENT LLC entered into AIA Standard Form Agreement (“contract”) with defendant GRUPPO 5 SUBPARTNERS INC., to complete a residential construction project (“Project”) on or about August 7, 2019. On June 14, 2022, Plaintiff filed a compliant alleging, breach of contract, unjust enrichment, common law indemnification, contractual indemnification, negligence, and breach of fiduciary duty, all in connection with the Project. On July 18, 2022, defendant appeared in this action, through counsel, and filed an answer to plaintiff’s complaint. Since then, the Court (Hon. N. Bannon J.S.C.) has scheduled two status conferences whereby the defendant failed to appear NY St Cts Elec Filing [NYSCEF] Doc No. 45, Status Conference Order, and NY St Cts Elec Filing [NYSCEF] Doc. No. 47, Status Conference Order). As a result of defendant’s failure to appear at the second status conference, the court “ORDERED that defendant Gruppo 5 Subpartners Inc., is held in default and its answer is stricken pursuant to 22 NYCRR 202.27″ (see NY St Cts Elec Filing [NYSCEF] Doc No. 47, Status Conference Order). By notice of motion (sequence number 005), dated February 15, 2024, plaintiff moved, pursuant to CPLR 3215, for an order granting it a default judgment against defendant. The Court denied said motion without prejudice to renewal within 30 days. The Court reasoned that plaintiff failed to satisfy the additional service requirements on a defendant corporation pursuant to CPLR 3215(g) (4) (ii) (see Decision and Order, dated March 12, 2024 [E. Morales-Minerva J.S.C.]). Within 30 days of the denial of plaintiff’s motion (sequence number 005), plaintiff filed the instant motion (sequence number 006), seeking an order granting them a default judgment. No defendants have appeared or submitted any opposition to the subject application. ANALYSIS A proponent for a default judgment must provide proof of service of the summons and complaint, proof of the facts constituting the claim, and proof of the default (CPLR 3215 [f]; see also Gordon Law Firm, P.C. v. Premier DNA Corp., 205 AD3d 416, 416 [1st Dept 2022]). Moreover, to plead breach of contract, the proponent must allege: (1) the existence of a contract, (2) the plaintiffs’ performance under the contract, (3) the defendants’ breach of that contract, and (4) resulting damages (see Second Source Funding, LLC v. Yellowstone Capital, LLC, 144 AD3d 445 [1st Dept. 2016]). Plaintiff has satisfied each of these elements to establish entitlement to a default judgment. First, Plaintiff has provided sufficient evidence to confirm defendant was properly served, and that the service defects in Motion Sequence 005 have been rectified in compliance CPLR 3215(g) and Business Corporation Law 303(b) (see NY St Cts Elec filing [NYSCEF] Doc No. 93, Affidavit of Brian L. Grossman). Second, Plaintiff offers an affidavit from Plaintiff’s sole manager, Ethem Gungor, in which he established the facts constituting the claim and damages incurred by plaintiff (see NY St Cts Elec filing [NYSCEF] Doc No. 77, Affidavit of Ethem Gungor). Specifically, Gungor states that the contract provided for $400.00 in liquidated damages per day if the project was not substantially completed by October 8, 2020, leading to $490,000.00 in liquidated damages as of the filing of this motion. Further, Gungor states, with exhibits attached thereto, that $16,500.00 was paid to Plaintiff’s neighbors to settle claims of damages caused by Defendant, $49,574.54 was paid by Plaintiff to subcontractors for work done that was originally contracted to be paid by Defendant, and $168,560.40 was paid by Plaintiff to Defendant for work that was never completed, demonstrated through Plaintiff’s business records (see NY St Cts Elec filing [NYSCEF] Doc No. 77, Affidavit of Ethem Gungor). It is well settled that a default judgment may be determinative of liability but not the amount of damages to be awarded, unless there can be no dispute as to the amount due, in other words, the amount sought being a “sum certain” see Arent Fox Kintner Plotkin & Kahn, PLLC v. Lurzer GmbH, 297 A.D.2d 590, 590 (1st Dept 2002); Reynolds Secs. v. Underwriters Bank & Trust Co., 44 N.Y.2d 568 (1978); see also CPLR 3215[a]). Further, a defendant whose answer is stricken, pursuant to 22 NYCRR 202.27, “admits all traversable allegations in the complaint, including the basic allegation of liability, but does not admit the plaintiff’s conclusion as to damages” (see Rokina Opt. Co., Inc. v. Camera King, Inc., 63 NY2d 728 [1984]). Where, however, the damages are for a sum certain, or a sum which can be made certain by computation, there is no need to conduct an inquest to assess the appropriate amount of damages (see Curiale v. Ardra Ins. Co., Ltd., 88 NY2d 268, 271 [1996]; see Transit Graphics v. Arco Distrib., 202 AD2d 241, 241 (1st Dept 1994). The affidavit of Ethem Gungor sufficiently sets forth the “sum certain” defendant owes as a result of the alleged breach; thus no inquest is necessary here. Accordingly, it is ORDERED that Plaintiff EIGHTEEN HARRISON MANAGEMENT LLC’S unopposed motion to enter default judgment against defendant GRUPPO 5 SUBPARTNERS INC., is granted; it is further ORDERED that the Clerk of the Court is directed to enter judgment against defendant GRUPPO 5 SUBPARTNERS INC., in the sum of $724,634.94, together with costs and disbursements; and it is further ORDERED that plaintiff shall serve a copy of this Decision and Order with notice of entry upon defendant within 30 days after entry. THIS CONSTITUTES THE DECISION AND ORDER OF THE COURT. CHECK ONE: X    CASE DISPOSED NON-FINAL DISPOSITION GRANTED DENIED X          GRANTED IN PART OTHER APPLICATION: SETTLE ORDER SUBMIT ORDER CHECK IF APPROPRIATE: INCLUDES TRANSFER/REASSIGN FIDUCIARY APPOINTMENT REFERENCE Dated: May 16, 2024

 
Reprints & Licensing
Mentioned in a Law.com story?

License our industry-leading legal content to extend your thought leadership and build your brand.

More From ALM

With this subscription you will receive unlimited access to high quality, online, on-demand premium content from well-respected faculty in the legal industry. This is perfect for attorneys licensed in multiple jurisdictions or for attorneys that have fulfilled their CLE requirement but need to access resourceful information for their practice areas.
View Now
Our Team Account subscription service is for legal teams of four or more attorneys. Each attorney is granted unlimited access to high quality, on-demand premium content from well-respected faculty in the legal industry along with administrative access to easily manage CLE for the entire team.
View Now
Gain access to some of the most knowledgeable and experienced attorneys with our 2 bundle options! Our Compliance bundles are curated by CLE Counselors and include current legal topics and challenges within the industry. Our second option allows you to build your bundle and strategically select the content that pertains to your needs. Both options are priced the same.
View Now
November 27, 2024
London

Celebrating achievement, excellence, and innovation in the legal profession in the UK.


Learn More
December 02, 2024 - December 03, 2024
Scottsdale, AZ

Join the industry's top owners, investors, developers, brokers and financiers for the real estate healthcare event of the year!


Learn More
December 11, 2024
Las Vegas, NV

This event shines a spotlight on how individuals and firms are changing the investment advisory industry where it matters most.


Learn More

INTELLECTUAL PROPERTY PROSECUTION PARALEGAL - NEW JERSEY OR NEW YORK OFFICESProminent mid-Atlantic law firm with multiple regional office lo...


Apply Now ›

The Republic of Palau Judiciary is seeking applicants for one Associate Justice position who will be assigned to the Appellate Division of ...


Apply Now ›

Experienced Insurance Defense Attorney.No in office requirement.Send resume to:


Apply Now ›